The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the Works and the remedying of defects therein the Contract Price or such other sum as may become payable under the provisions of the Contract at the time and in the manner prescribed by the Contract.
(2)covenant: v. make a formal agreement 立约,签订合同、条约; n. legal agreement具有法律约束的正式合同
(3)completion of the Works: 工程的竣工
(4)therein: in the Works在本工程中
(5)the Contract Price: 合同总价,指工程的总造价
(6)such...as: 关系代词,相当于that, which
(7)under: in accordance with 根据,按照
(8)the provisions of the Contract: terms and conditions of the Contract合同条款
例2:
We hereby certify to the best of our knowledge that the foregoing statement is true and correct and all available information and data have been supplied herein, and that we agree to provide documentary proof upon your request.
注释:
(1)hereby:特此
(2)to the best of our knowledge:as far as we know据我们所知
This Contract is hereby made and concluded by and between Co. (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B) on (Date), in (Place), China, on the principle of equality and mutual benefit and through amicable consultation.
注释:
(1)hereby:特此
(2)hereinafter referred to as Party A:以下称甲方
(3)on the principle of equality and mutual benefit:在平等互利基础上
This agreement is hereby made and entered into on (Date), by and between Co. China (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B).
注释:
(1)this agreement is hereby made and entered into:特此订立本协议 在法律文件中表示“订立本协议”可用以下4个动词:sign (make, conclude or enter into) this agreement, 按照同义词连用的写作特点,可用上述4个动词中的两个来表示)。
(2)hereinafter referred to as Party B:以下简称乙方
参考译文:
本协议特由中国 公司(以下简称甲方)与 公司(以下简称乙方)于 年 月 日订立。
二 hereof
英文释义: of this
中文译词:关于此点;在本文件中
用法:在表示上文已提及的“本合同的、本文件的.??”时,使用该词。例如表示本合同条件、条款时,可以说“the terms, conditions and provisions hereof”,这里hereof表示“of this Contract”;又如表示本工程的任何部分,可用“any parts hereof”,这里hereof表示“of this Works”。 语法:一般置于要修饰的名词的后面,与之紧邻。
hereof和thereof的区别:hereof强调“of this”。例如,上面的“the terms, conditions and provisions thereof”中的thereof表示of the Contract;“any parts thereof”中的thereof表示of the Works。
Whether the custom of the Port is contrary to this Clause or not, the owner of the goods shall, without interruption, by day and night, including Sundays and holidays (if required by the carrier), supply and take
delivery of the goods. Provided that the owner of the goods shall be liable for all losses or damages including demurrage incurred in default on the provisions hereof.
注释:
(1) Whether the custom of the Port is contrary to this Clause or not:不论港口习惯是否与本款规定相反,whether? or not:不论??是否
(2) the owner of the goods:货方
(3) without interruption:无间断地
(4) carrier:承运人
(5) in default on the provisions hereof:违反本款规定 hereof:of this Clause
Foreign trade dealers as mentioned in this Law shall, in accordance with the provisions hereof, cover such legal entities and other organization as are engaged in foreign trade dealings.
注释:
(1) foreign trade dealers:对外贸易经营者
(2) as mentioned in this Law:本法所称
(3) the provisions hereof:the provisions of this Law 本法规定
(4) legal entity:法人
(5) be engaged in foreign trade dealings:从事对外贸易经营活动 参考译文:
本法所称对外贸易经营者,是指依照本法规定从事对外贸易经营活动的法人和其他组织。
The establishment of a limited liability company or a company limited by shares shall comply with the conditions and provisions of this Law. A company complying with the conditions and provisions hereof may be registered as a limited liability company or a company limited by shares. Provided that if a company fails to comply with the conditions and provisions hereof, the company in question shall not be registered as a limited liability company or a company limited by shares.
If, as a result of withdrawal or any other reasons, an arbitrator fails to perform his duties as an arbitrator, another arbitrator shall, in accordance with the provisions hereof, be selected or appointed. 注释:
(1) as a result of withdrawal or any other reasons:回避或者其它原因
(2) arbitrator:仲裁员
(3) the provisions hereof:the provisions of this Law 本法规定
In the event of conflict between the provisions on arbitration formulated and prepared prior to the effective date of this Law and the provisions of this Law, the provisions hereof shall prevail.
注释:
(1) conflict:相抵触
(2) prior to the effective date of this Law:本法施行前
(3) the provisions hereof shall prevail:以本法为准 hereof:of this Law 参考译文:
本法施行前制定的有关仲裁的规定与本法的规定相抵触的,以本法为准。 例6
Where, in accordance with laws, the circumstance(s) specified in Article 15 and Article 16 of this Law is /are confirmed, the organization with compensatory obligations shall pay compensation in any of the circumstance in question.
Where the claimant for compensation demands the confirmation of one of the circumstances specified in Article 15 and Article 16 hereof, and the demanded organization refuses to make the confirmation, the claimant shall have the right to lodge a complaint. Where the claimant claims compensation, the claim, shall, first, be lodged to the organization for compensatory obligations.
The provisions of Article 10, Article 11 and Article 12 hereof shall apply to/ in the procedures of compensation.
注释:
(1) the organization with compensatory obligations:赔偿义务机关
(2) shall pay compensation:应当给予赔偿
(3) the claimant for compensation:赔偿请求人
(4) Article 15 and Article 16 hereof:本法第十五条、第十六条 hereof:of this Law
(5) shall have the right to lodge a complaint:有权申诉
(6) claims compensation:要求赔偿
(7) apply to/ in:适用 More Examples: The comment applies equally here. /That argument does not apply in this case. /That applies to at least nine-tenths of the people we see about. /These remarks apply to every town in this kingdom. /The rules of safe driving apply to everyone. 参考译文:
If an arbitrator involved in one of circumstances specified in Item 4, Article 34 of this Law, and if it is serious, or those specified in Item 6, Article 58 hereof, the arbitrator in question shall, in accordance with the law, bear the legal liability and responsibility. The arbitration commission shall remove the name of the arbitrator in question from the list of arbitrators.
注释:
(1) arbitrator:仲裁员
(2) Article 58 hereof:本法第五十八条 hereof:of this Law
(3) bear the legal liability and responsibility:承担法律责任
(4) the arbitration commission:仲裁委员会
(5) remove the name of the arbitrator in question from the list of arbitrators:将其除名
If, pursuant to this Law, the relevant responsible authorities with the duty of approvals fail to grant approval to such an application as meets the requirements and provisions hereof, or the company registration authorities fail to register a company whose application meets the requirements hereof, the party in question may, in accordance with laws, apply for reconsideration or bring an administrative suit.
注释:
(1) the relevant responsible authorities with the duty of approvals:履行审批职责的有关主管部门
(2) meets the requirements and provisions hereof:符合本法条件
(3) the company registration authorities:负责公司登记的主管部门
(4) the requirements hereof:本法条件 hereof: of this Law
(5) apply for reconsideration:申请复议
(6) bring an administrative suit:提起行政诉讼
并购英文合同范本 第2篇
编号:
Contract No:
日期:
Date:
签约地点:
Signed at:
卖方:
Sellers:
地址:
Address:
邮政编码:
Postal Code:
电话:
Tel:
传真:
Fax:
买方:
Buyers:
地址:
Address:
邮政编码:
Postal Code:
电话:
Tel: 传真:
Fax:
兹确认售予买方下列货品,其成交条款如下:
The Seller hereby confirms selling the following goods on terms and conditions
(1)公差:数量及总值均有_____%的增减,由卖方决定
Tolerance: With _____% more or less both in amount and quantity allowed at the
sellers option.
(2) 原产地
Country of Origin:
(3) 付款方式:30%预付,70%发货前一周付清.
Payment terms: 30% deposit, 70% payment within one week before delivery.
(4) 交货时间:收到预付款后15天内完成装运。
Time of shipment: Within15 days after deposit received.
(5) 贸易方式:FOB Shanghai
Terms of Shipment: FOB Shanghai
(6) 包装:胶合板木盘外封铁皮
Packing: Plywood drum with steel sheet cover.
(7) 保险:由卖方按发票全额110%投保至_____为止的_____险。
Insurance: To be effected by seller for 110% of full invoice value covering _____ up to _____ only.
(8) 装运口岸:中国上海港
Port of Loading: Shanghai Port, China
(9) 转运:允许
Transshipment: Allowed
(10 分批装运:允许分批装运
Partial Shipment: Allowed
(11) 目的口岸:
Port of Destination:
(12) 唛头:Shipping Marks:
(13) 单据:Documents:
(14) 品质与数量、重量的异义与索赔:Quality/Quantity Discrepancy and Claim:
LAST SHIPMENT: if the late delivery is caused by the buyer, the buyer shall bear the
responsibility. If the delay has being made more than 45 days from the signing of the Sales Contract hereof, the buyer shall pay 3% of total amount each day, and if the delay is more than 6 months, the Seller has the right to dispose the down payment and the goods. If the late delivery is caused by the Seller, the Seller shall inform the Buyer in advance and get confirmation from the Buyer, and the related expense shall be born by the Seller.
(16) 质量/数量异议:对于质量方面的异议,买方必须在货物抵达目的港后30天之类提出:对于数量方面的异议,买方必须在货物抵达目的港后15天之内提出。对由于保险公司、运输公司、其他运输机构或邮局的原因所造成的货物差异,卖方不负任何责任。 QUALITY/QUANTITY DISCREPANCY: In case of quality discrepancy, claim shall be filed by the Buyer within 30 days after the arrival of the goods at port of destination; while for quantity discrepancy, claim shall be filed by the buyer within 15 days after the arrival of the goods at port of destination. It is understood that the Seller shall not be liable, for any discrepancy of goods shipped due to causes for which the Insurance Company, Shipping Company, other transportation organization or Post Office are liable.
FORCE MAJEURE: Seller shall not be responsible for failure or delay in performance of entire or portion of these Sale Contract obligations in consequence of Force Majeure incidents: flood, fire, earthquake, drought, war, or any other matters couldn’t be foreseen or controlled or couldn’t be avoided. But Seller shall inform the incidents to Buyer immediately, and shall delivery the certificate of Force Majeure incidents issued by related organization within 15 days after the incidents happened. If the incidents influence more than 120 days, both parties shall negotiate to decide whether to execute or terminate the Sales Contract.
ARBITRATION: All disputes across from the execution of, or in connection with this Sales Contract shall be settled friendly through negotiation, in case no settlement can be reached, the case shall then be submitted to China International Economic and
Trade Arbitration Commission, Beijing for arbitration in accordance with its provisional rules of procedure. The result of arbitration shall be born by the losing party except for the condition the Commission has other judgment. During the arbitration period, clauses beside of the arbitrated parts shall be executed.
The Sales Contract is concluded in Chinese and English with same effectiveness, and will come into effect on stamp of Seller and signing by Buyer. The Sales Contract is in dual original and each party shall have one original copy of this Sales Contract. (Any scanned and faxed copy shall have the same legal effect as the original one.)
(20) 备注:
Remark:
买方确认签署: 卖方确认签署:
For and on behalf of Buyer: For and on behalf of Seller:
This purchase contract (hereafter abbreviated “contract”) is signed by and between the Buyer and the Seller upon equal negotiations based on the Contract Law of P..R .China and other relevant laws and
regulations.. Both parties agree to sell and buy goods on following terms and conditions.
Purchasing Contract terms and conditions of ***garments Season: ***服装采购合同条款:
1. Description, quantity, unit price, total amount and
other details of the goods ordered please refer to detail order, invoice and packing list. The name of the issuing company of invoice must be the same as the seller.
Delivery: The seller shall deliver the goods to the warehouse as previously agreed between the two parties.
交货方式:卖方应把货物送交至双方事先约定的仓库。
The quality of all the garments shall answer for the updated, valid Standard of the Nation and the industry. In case the garments are unqualified or for other reason that shall ascribe the seller’s fault, which brings losses of or damages (including but not limited to fine, expropriate, damage to Goodwill, lawyer’s fee and other losses for the buyer ’s breach of law or
contract because of the seller fault) to the buyer, the buyer shall has the right to ask seller for damages.
Seller shall provide 7 original copies of _Approved_ Quality Inspection Certificate for each fabric used to produce
MOTIVI different models 7 days before the delivery date. The certificate must be issued by a Chinese official quality testing
department, the samples that the seller send to quality test lab shall be representative, can represent the quality of the goods, and the test must follow the Basic Standard GB18401 and include the composition of the fabric. The buyer will settle the payment according to the contract after received the test report and other related documentations (Packing list, Invoice of Goods etc.).
4. For all the goods, the seller shall issue invoice to the buyer, the invoice shall be invoiced to: *** Co., Ltd
所有货物应由卖方向买方开具发票,发票抬头需开列买方单位名称为***有限公司。
Kind of invoice issued: People’s Republic of China VAT invoice 发票开立种类:_增值税专用发票。
5. Terms of Payment: Total amount of payment of goods shall be paid in RMB within 30 days issued the invoices.
付款方式:买方向卖方所订购的货物款项皆以人民币支付,具发票后30天内支付本合同的100%货款。
Upon signing the contract, the seller shall provide bank information for the buyer to effect payment.
买卖双方签定订购合同后,卖方需提供公司银行资料给予买方支付货款.。 Payee:
帐户名称
Bank:
开户银行
A/_o.:
开户帐号
6. Intellectual Property Right
All the goods, documents and materials that the Seller gets to may concerns intellectual property right of the buyer and *** Group, especially may contains trade marks, copyright and business
secret of the buyer and *** group. The seller shall keep secret and shall procure that its employee, agent and any other persons who may have access to the above-mentioned information keep
confidentiality and shall not use it for any purpose at any time or disclose to any third party. The seller shall not
sell, transfer any products or materials to any third party except for the buyer and *** group that concerns trade marks, other logo or marks, copyright and other intellectual property right of the buyer and *** group, even if for the out season products, substandard products, rest products and unused/waste products or materials. In case the seller breaches, the buyer has the right to ask for indemnification including but not limited investigation fees, lawyer’s fees,compensation as well as all other fees according to the stipulations or Chinese laws.
7. Both parties will try to resolve any dispute concerning the contract amicably. If the dispute can not be resolved by negotiation, any party may initial legal action.
买卖双方在履行本合同时如有争议应先以友好协商方式解决,如协商不成买卖双
方可将争议送交由提出诉讼方所在地之人民法院进行诉讼.
All appendixes to this contract should be bonded to the contract as a whole. 本合同所附带之所有附件及附带协议或合同将作为本合同不可分离之一部份. The contract includes two originals signed by the authorized signatories from each party on the following date, each party shall retain one fully signed originals and each copy has equal legal effect.
This agreement is written in one form of two versions in English and Chinese, if both versions of English and Chinese are found inconsistent, the Chinese version should be the basis to follow.
SECTION 4 SCOPE OF PLEDGE AND REDELIVERY OF THE PLEDGED COLLATERAL
第四条 承诺抵押品的抵押范围及重新发运
SECTION 5 REPRESENTATIONS AND WARRANTIES 第五条 陈述与保证
SECTION 6 AFFIRMATIVE COVENANTS 第六条 肯定性条款
SECTION 7 APPOINTMENT OF AGENTS AND ACTIONS BY LENDER
第七条 代理人指定及贷方行为
SECTION 8 SALE AND TREATMENT OF PLEDGED COLLATERAL
第八条 承诺抵押品的出售及处理
SECTION 9 DIVIDENDS AND VOTING RIGHTS 第九条 股息及表决权
SECTION 10 RIGHTS AND REMEDIES 第十条 权利及赔偿
SECTION 11 APPLICATION OF PROCEEDS OF PLEDGED COLLATERAL IN EVENT OF
DEFAULT
第十一条 违约情况下承诺抵押品的收益应用
SECTION 12 COMPLIANCE WITH SECURITIES LAWS
第十二条 有价证券法律的遵守
SECTION 13 MONETARY RELIEF 第十三条 货币补偿
SECTION 14 MISCELLANEOUS 第十四条 其他款项
SECTION 1 第一条 DEFINITION 定义
Use of Defined Terms. Unless otherwise expressly specified herein, defined terms denoting the singular number shall, when in the plural form, denote the plural number of the matter or item to which such defined terms refer, and vice-versa. The Section, Schedule and Exhibit headings used in this Pledge Agreement are descriptive only and shall not affect the construction or meaning of any provision of this Agreement. Unless otherwise specified, the words “hereof,” “herein,” “hereunder” and other similar words refer to this Pledge Agreement as a whole and not just to the Section, subsection or clause in which they are used; and the words “this Agreement” refer to this Pledge Agreement. Unless otherwise specified, references to Sections, Recitals,
Schedules and Exhibits are references to Sections of, and Recitals, Schedules and Exhibits to this Agreement.
Statements as to Knowledge. Any statements, representations or warranties which are based upon the knowledge of the Pledgor shall be deemed to have been made after due inquiry with respect to the matter in question.
认知声明。在抵押人认知基础上的任何声明,陈述或保证均应被视为在对所涉及事宜进行正当询问之后做出。
SECTION 2 第二条 PLEDGE 质押
Pledge by Pledgor. The Pledgor hereby pledges, and assigns to the Lender, and hereby transfers to the Lender all right, title, ownership and interest in and to (all the foregoing herein called the “Pledge”), the following described property hereinafter called the “Pledged Collateral”: the ______ shares of ______ ( ), together with any certificates, whether physical or electronic, evidencing such shares (collectively, the “Pledged Shares”) and all cash, instruments, securities or other property representing a dividend or other distribution on any of the Pledged Shares, or representing a distribution or return of capital upon or in respect of the Pledged Shares, or
resulting from a split-up, revision, reclassification or other like change of the Pledged Shares or otherwise received in exchange therefore, and any warrants, rights or options issued to the holders of, or otherwise in respect of, the Pledged Shares, and all proceeds thereof (collectively, the “Pledged Collateral”).
Non-Recourse Loan and Pledge. The Lender agrees, for itself, its representatives, successors and assigns that: (i) neither the Pledgor, nor any representative, successor, assign or affiliate of the Pledgor, shall be personally liable for the Principal Loan Amount; and (ii) the Lender, and any such representative, successor or assignee, shall look only to the property identified in this Pledge Agreement for payment of the Obligations and will not make any claim or institute any action or
proceeding against the Pledgor, or any representatives, successors, assigns or affiliate of the Pledgor, for any deficiency remaining after collection upon the Pledged Collateral, except as provided below.
Provided, however, notwithstanding the foregoing, the Pledgor is and will remain personally liable for any deficiency remaining after collection of the Pledges Collateral to the extent of any loss suffered by Lender, or its representatives, successors, endorsees or assigns, is caused by Pledgor based in whole or in part upon damages arising from any fraud, misrepresentations or the breach of any representation, warranty or agreement in the Loan Documents.
SECTION 4 SCOPE OF PLEDGE AND REDELIVERY OF THE PLEDGED COLLATERAL
第四条 承诺抵押品的抵押范围及重新发运
Pledge Absolute. The Pledgor hereby agrees that this Pledge Agreement shall be binding upon the Pledgor and that the Pledge of the Pledged Collateral hereunder shall be binding upon the Pledgor and that the Pledge of the Pledged Collateral hereunder shall be irrevocable and
unconditional, irrespective of the validity, legality or enforceability of the Loan Agreement and any other Loan Document, even in the absence of any action to enforce the same, the waiver or consent by the Lender with respect to any provision thereof, or any action to enforce the same or any other similar circumstances. The Pledgor hereby waives diligence, presentment, demand of payment, filing of claims with a court in the event of merger or bankruptcy of the Pledgor, any
notice to require a proceeding first against the Pledgor or any other Person, protest or notice with respect to indebtedness evidenced hereby and all demands whatsoever, and covenants that this Agreement will remain in full force and effect so long as any Obligations under the Loan Agreement remains unpaid.
Termination and Redelivery of the Pledged Collateral. This Agreement shall terminate when all of the Pledgor’s Obligations have been paid in full. Within five business days of the Pledgor’s satisfaction of the Obligations, the Lender shall reassign all right, title, ownership and interest in identical securities, as described in IRC 1058 to the Pledgor and redeliver the Pledged Collateral, without recourse or warranty, at the sole expense of the Lender. The Lender shall also deliver appropriate instruments of reassignment and release. Provided, however, that this Agreement shall be reinstated if any payment in respect of the Obligations is rescinded, invalidated, declared to be fraudulent or preferential or otherwise required to be restored or returned by the Lender for any reason, including without limitation by reason of the insolvency or bankruptcy of the Pledgor or any other person. For the purpose of this Pledge Agreement and the Loan Documents, a return of identical securities means a return of the Pledged Shares as modified as a result of any split-up, revision, reclassification or other like change of the Pledged Shares. Any cash or shares tendered to buy down the Loan due to the occurrence of an Event of Default are not subject to redelivery and do not become part of the Pledged Collateral.